Architects and Delay Analysis

You’re a Property Developer who typically acts as a Main Contractor on projects. During a recent project you experienced programme issues relating to the design team and suffered delays that extended the overall programme.

At the outset of the project you formulated a master programme with the Architect, which included a 16-week construction design programme. The actual design took 30-weeks for the Architect to complete owing to some external matters with Network Rail, but also poor coordination and under-resourcing by the Architect.

We put together this scenario to Jason Farnell, Adjudicator and CEDR Accredited Mediator from Commercial Risk Management.

The C-Link Ebooks count towards your RICS informal CPD hours. Don’t forget to log them!

Receive resource via email

What’s in this book?

There was a 14-week design delay. We accept some of the matters were 3rd party (Network Rail) related, however the Design Team was under resourced throughout. What is the best way to analyse and evidence this delay to clarify the breakdown of responsibility?
The master programme was included within the Architect’s order but there was no provision for delay damages. We suffered extra costs due to the delays, are we entitled to recover these? If so, how do we best do this?
For future projects, what is your best advice for drafting contracts with the Design Team?

Please fill out the information below to enable your download

First name *
Last name *
Company name *
Job Title *
Mobile Phone *
Email address *
Country / Region *
Segment *
Are you tendering with subcontractors?
How can C-Link help you with your tendering needs?
Are you using excel, dropbox, sharepoint, onedrive to manage tendering?
On a single subcontract package, on average how long are you spending finding subbies, creating tenders and issuing contracts?
Accept terms & add me to your email list View terms & conditions

Receive resource via email